Hydropower project contract (selected 5 articles)

Dear friends, bidders can be individual citizens, groups or corporate legal persons, and the winner of the bid through competition is the business operator. I am here to share with you some hydropower project contract contracts, hoping it will be helpful to you.

Hydropower Project Contract Part 1

Contractor: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Guarantor: (hereinafter referred to as Party C)

After full negotiation between Party A and Party B, the following agreement has been reached regarding Party B's contracting to operate Party A's bathing center, and both parties shall abide by it.

1. Subject of the contract

Party A contracts the bathing center located in to Party B for operation. Party B has fully understood the current status of all leisure centers owned by Party A, and is willing to contract and operate the above-mentioned leisure centers of Party A and ensure legal operation.

2. Operation method

During the contract operation period, Party B shall implement independent accounting, be responsible for its own profits and losses, and operate independently.

3. Contracting period

1. The contracting operation period is years, that is, from year, month, day to year, month, day.

2. If the performance of the agreement is canceled or terminated in advance in accordance with legal provisions or this agreement, it will not be restricted by the above period.

IV. Contracting Fee and Payment Method

The contracting fee for Party B’s contract to operate the bathing center is ______ yuan/year, and the principle of payment first and use later shall be followed; Party B shall pay the fee in the following manner to Party A pays the contract fee:

_______________;

_______________;

5. Party A’s rights and obligations

1. Party A

2. Party A will hand over to Party B the various certificates and licenses required for the operation of the bathing center on the date of signing this agreement.

3. After signing this agreement, Party A shall hand over the bathing center to Party B for use in a timely manner.

4. Party A has legal ownership of the facilities, equipment and other assets transferred to Party B for contract operation and management, and has the right to supervise.

6. Rights and Obligations of Party B

1. Party B shall pay the contracting fee in full and in a timely manner as agreed.

2. Party B shall carry out various business activities within the scope of authorization of the industrial and commercial administration department and Party A.

3. Party B shall bear all water and electricity expenses during the operation period, annual license inspection related expenses and other fees charged by relevant departments.

4. During the contract period, Party B has the right to use the assets, facilities and equipment provided by Party A and must keep the equipment in good condition. If the facilities are naturally damaged due to expiration of their service life, Party B shall promptly report them to Party A for review and then scrap them, and Party B shall not dispose of them without authorization.

5. Party B shall not violate national policies and laws in its operations, otherwise Party B will be responsible for the consequences and financial responsibility.

6. Without the consent of Party A, Party A’s property shall not be used to provide guarantees to external parties, and Party A’s property shall not be disposed of without authorization.

7. Party B shall not transfer the bathing center to a third party during the operation process. Once discovered, Party A has the right to terminate the contract at any time and hold Party B liable for breach of contract.

8. Party B shall not provide guarantees or engage in business activities unrelated to the business scope in the name of the bathing center.

9. Party B shall regularly inspect, maintain and maintain the fire-fighting equipment and facilities in the bathing center. Party B shall be solely responsible for any disasters caused by failure of fire-fighting facilities to meet standards.

10. Party B shall hand over all valid certificates and licenses to Party A on the date of cancellation or termination of this agreement.

7. Guarantee or security deposit

Party C voluntarily provides Party A with joint liability guarantee for all obligations of Party B under the framework of this agreement. The period of guarantee provided by Party C is two years.

Party B pays a deposit of _____ yuan to Party A. If Party B breaches the contract, the deposit shall belong to Party A and Party B shall not claim for its return. If Party B has no breach of contract, Party A shall promptly return the deposit after the agreement is terminated or terminated.

8. Liability for breach of contract

Party A and Party B shall fully perform the provisions of this agreement. If either party breaches the contract, the observant party shall have the right to terminate the agreement in advance or terminate the performance of this agreement. The breaching party shall bear liquidated damages of ______ yuan to the non-defaulting party; if the liquidated damages are insufficient to compensate for the losses of the non-defaulting party, the non-defaulting party shall also be compensated for the losses.

9. Others

1. After the expiration of the agreement, if Party A re-contracts operations, Party B will have priority in contracting operations under the same conditions.

2. After the agreement expires or is terminated, the original equipment and facilities will be owned by Party A, and the equipment and facilities added by Party B will be owned by Party B. Party A can obtain this part of the equipment and facilities at a discount.

3. If there are any matters not covered in the agreement, Party A and Party B shall make additional provisions through consultation. Supplementary terms have the same effect as this Agreement.

10. This agreement will take effect after being signed by both parties.

11. This agreement is made in triplicate, with Party A and Party B and the guarantor each holding one copy.

Party A: Party B:

Guarantor:

Year, month, year, month, day, hydropower project contract, Part 2

Contract ：Field contract contract

Parties to the contract

Name of Party A: Name of Party B:

Basis of the contract

In order to regulate rural land contract management rights Transfer behavior, safeguard the legitimate rights and interests of both parties to the transfer, and promote the development of agriculture and rural economy. According to the "Rural Land Contract Law of the People's Republic of China", the "Measures for the Administration of the Transfer of Rural Land Contract Management Rights of the People's Republic of China", etc. Relevant laws, regulations and policies, based on the principles of voluntariness, mutual benefit, fairness and equality, and after negotiation between Party A and Party B, the following land contract management rights transfer contract is entered into [1]: Contract content

1. Transfer of land contract management rights Method: Party A adopts a method to transfer its contracted land to Party B for operation.

2. Use of the transferred land: Party B shall not change the agricultural use of the transferred land and use it for non-agricultural production. The parties to the contract have agreed:

3. The term and start and end date of the transfer: agreed by both parties to the contract , the land contract management right transfer period is x years, starting from x, month, x, year x, and ending on x, month x, year x.

4. Type, location, area and grade of transferred land: Party A will transfer x acres of contracted farmland (wasteland, forest land and other land) to Party B, and the specific location (name, four to) of the land. (A detailed list can be provided, and a plan of the current land status can be attached).

5. Transfer price, payment method and time: Both parties to the contract agreed that the land transfer fee should be paid in cash (in kind). Party B shall pay Party A x yuan/mu (or x kilograms/mu in kind) every year (time, or one time), totaling x yuan (or x kilograms in kind).

6. Rights and obligations of Party A:

(1) Rights: Collect land transfer fees in accordance with the contract, and recover the transferred land upon expiration in accordance with the contract.

(2) Obligations: Assist Party B in exercising land management rights in accordance with the contract, help mediate disputes over water and electricity use between Party B and other contractors, and shall not interfere with Party B’s normal production and operation activities.

7. Rights and obligations of Party B:

(1) Rights: Has the right to produce and operate the transferred land.

(2) Obligations: Engage in production and business activities within the scope permitted by national laws, regulations and policies, pay land transfer fees in full and on time in accordance with the contract, and shall not change the use of the transferred land without authorization, and shall not make it Barrenness, effective protection of transferred cultivated land (wasteland, forestland, etc.).

8. Modification and termination of the contract: This contract may be modified or terminated under any of the following circumstances:

(1) Upon consensus reached by both parties without prejudice to the interests of the country, the Collective and individual interests;

(2) There are major adjustments and changes in the national policies on which the contract is concluded;

(3) One party breaches the contract, making it impossible to perform the contract; < /p>

(4) The contract cannot be performed due to Party B’s loss of business capabilities;

(5) The contract cannot be performed due to force majeure.

9. Liability for breach of contract:

(1) If Party A illegally interferes with Party B’s production and operation, changes or terminates the contract without authorization, causing losses to Party B, Party A shall compensate Party B for the losses.

(2) Party B shall be liable for compensation if Party B violates the provisions of the contract and causes losses to Party A.

(3) Party A has the right to take back the land management rights if Party B has any of the following circumstances: does not use the land according to the purpose specified in the contract; neglects the land and destroys attachments on the ground; fails to pay land transfer fees on time It's free.

10. Resolution of contract disputes: If a dispute arises between Party A and Party B due to the performance of the transfer contract, it shall first be resolved through negotiation between the two parties. If the negotiation fails, it shall be resolved through mediation by the village committee, township (town) people's government, sub-district office, etc. . If they do not agree to the mediation or the mediation is invalid, the two parties shall negotiate to apply for arbitration to the county-level Rural Land Contract Dispute Arbitration Committee, or they may directly file a lawsuit with the People's Court. If you are dissatisfied with the arbitration decision, you may file a lawsuit in the People's Court within 30 days from the date of receipt of the award.

11. Other agreed matters:

(1) This contract is made in four copies, one each for Party A, Party B and the original contractor, and the township rural land contract management agency One serving. It shall take effect from the date of signature or seal of Party A and Party B. If it is a farmland transfer contract or a professional production and operation project transfer contract, it shall take effect on the date of consent of the original contract-issuing party.

(2) Other matters agreed upon by Party A and Party B of the contract.

(3) For matters not covered in this contract, Party A and Party B shall negotiate together to reach an agreement and form a written supplementary agreement. The supplementary agreement has the same legal effect as this contract.

Party A’s signature: Party B’s signature:

Year, month, year, month, year, month, day, water and electricity project contract, Part 3

Party A: ____________________ (hereinafter referred to as Party A)

Party B: _______________ (hereinafter referred to as Party B)

In accordance with the relevant spirit of the "Contract Law of the People's Republic of China" and the "Construction Project Contract Regulations", after negotiation between Party A and Party B , Party A agrees to contract the labor services of the _____ project of this project to Party B. In order to clarify the rights and obligations of both parties, the following agreement terms are signed for both parties to abide by.

1. Project name and location

This project is a teaching laboratory building project of a school in Changsha, located in Changsha Sports New City.

2. Contracting Methods and Requirements

Party A of this project adopts the method of dividing the work type and combining the unit price into a total price, and contracts it to Party B on the basis of including tax, labor, food and accommodation. The contracting team is required to have labor contracting qualifications, have employment certificates for major types of work, and prepare a personnel roster and submit it to Party A for archival purposes.

3. Project Contracting Unit Price and Content

After negotiation between the two parties, the _______ project will be contracted by Party B at a unit contracting price of _______ yuan/(m2, m3, t) , the unit contract price includes the following: completion of a full set of construction drawings, disclosure minutes, and changes related to the construction provided by the builder; on-site organization and cleanup; horizontal ground transportation within 200 meters; maintenance and upkeep of production equipment; maintenance of materials Saving; cooperating with other teams, etc.

4. Project Quality and Safety

According to the requirements of the owner, the quality of this project must be excellent, so individual contracting must ensure excellent quality. If the quality of this project is assessed as an excellent project, Party A Appropriate rewards will be given. If a single contract item is assessed as unqualified, Party B will rework and repair it until it is qualified. All economic losses caused by the rework will be borne by Party B and will be deducted from Party B's labor settlement.

Party B's construction workers must obey the arrangements of Party A's management personnel and must strictly abide by the "Safety Operating Procedures". In order to enhance workers' safety awareness, team leaders and team leaders must arrange their workload every day and conduct safety briefings. Education, emphasizing safe operations, wearing safety helmets, installing safety nets and fastening seat belts, and doing various safety protection tasks to prevent safety accidents. Party B will be responsible for any safety accidents caused by Party B, and Party A does not assume any economic or legal responsibility.

5. Civilized Construction and Rewards and Punishments

Party B’s personnel entering the construction site must abide by the civilized construction manual, complete the work and materials within the scope of their contract, and clean up the site strictly. Material conservation is a key issue, and random sawing, littering, and wasting of materials are not allowed. If found, fines will be imposed after responsibilities are clarified. At the same time, the person in charge of Party B must manage his own team. Personnel outside Changsha City must apply for a "temporary residence permit" before entering the site. Suspected SARS patients are strictly prohibited from entering the construction site. They must strictly abide by the public security management regulations. Violators will be fined. Party B’s personnel must obey the instructions of the management personnel and abide by all rules and regulations of the construction site. Submit ID card and family planning certificate to Party A. Those under the legal age are not allowed to work on the construction site. Anyone who violates the regulations will be punished according to the relevant regulations of the project department.

6. Payment method and construction period:

After Party B’s team enters the project, Party B will be responsible for its upfront expenses. Party A will lend Party B a certain amount of living expenses based on the progress of the project. The subject's cap payment is 50% of the labor fee. 70% of the labor fee will be paid upon completion of the project. After the project is settled, 90% of the labor fee will be paid. 10% will be left to be paid off within one month after the warranty expires. Due to the tight construction period of this project and the strict rewards and penalties imposed by the owner, in order to ensure that the project is completed on time, Party B must pay a construction period deposit of _______ million yuan before entering the site. At the construction site, Party B must carefully organize and construct carefully according to the construction period control points determined by Party A to ensure the realization of the construction period goals. If the construction period is delayed due to Party B's reasons. In addition to deducting the construction period security deposit, penalties will be imposed according to the contract signed between Party A and the owner.

7. Rights and Obligations of both Parties

(1) Party A

1. Party A has the right to conduct a qualification review of Party B and punish Party B for violating the terms of the contract. The power to impose penalties, financial compensation and dismissal.

2. Party A shall arrange for Party B to implement the project contract content according to the project requirements, and Party B shall comply with it unconditionally.

3. Party A provides Party B with the most convenient construction conditions possible, and pays labor fees in accordance with the labor contract and the owner’s payment status.

4. Party A will implement a real-name system for the construction workers provided by Party B, establish health status files, and all workers with disabilities and intellectual disabilities will be removed and will not be allowed to enter the construction site.

(2) Party B

1. Party B must submit to Party A a contract that meets the contracting qualifications and has the right to make legal demands on Party A, take the initiative to undertake all the work in the contract, and ensure the quality of the project .

2. Owner B must carry out safe production in accordance with Party A’s requirements. Party B shall not violate safety operating procedures without authorization. Party B must bear full responsibility for personal injuries and death accidents that occur in violation of safe operating procedures. Party A No responsibility is assumed.

3. Party B has the right to reject Party A’s instructions that do not meet the safety production requirements and put forward its own opinions for Party A’s reference.

4. Party B shall not use workers with disabilities or intellectual disabilities, and shall not conceal them or use them without permission. At the same time, Party B should provide a list of personnel and ID cards.

5. Party B must manage its own team and shall not engage in illegal and criminal activities at the construction site and outside, such as gambling, prostitution, whoring, etc. Party A will not be responsible for the consequences of a crime once it occurs.

6. In order to ensure the construction period, Party B must ensure sufficient labor force for the project according to Party A’s requirements and must not be passive in work.

8. Liability for breach of contract and others

1. Both parties must strictly abide by the above terms. If any party violates or causes the project to stop work, the defaulting party must be held accountable.

2. If the company's reputation, on-site equipment and certain economic losses are caused to the project due to Party B's fault, Party A has the right to require Party B to compensate for all losses and deduct them from the contracted labor fee.

3. Party B must keep its own equipment, tools and utensils, etc., and shall not make other demands on Party A, let alone make excuses to affect the quality and progress of the project. The losses shall be borne by Party B.

4. This contract is made in triplicate, two copies for Party A and one for Party B. It will take effect after being signed by both parties.

This Agreement is made in duplicate, with each party holding one copy and having the same legal effect.

Party A: ______________

Representative: ______________

_____year_____month____day

Party B: ______________ < /p>

Representative: ______________

Hydropower Project Contracting Contract Part 4 of _____, _____, month, ____

Party A: __× Company

Party B:

The company is a limited liability company jointly established by Party A and Party B and approved in accordance with the law. After mutual negotiation between Party A and Party B, the company is contracted to Party A The parties have reached an agreement on matters related to Party A's operation as follows:

1. The company contracts to Party A for operation, starting from the year, month and day, and counting the years.

2. During the contract period, Party A must ensure that the contract payment is RMB 10,000 per year. The contract payment will be reflected in the company’s financial accounting statements and shall be paid by Party A within two months after the end of each fiscal year. , Party B shall distribute dividends in accordance with legal provisions. The profit exceeding the contract payment belongs to Party A.

3. During the contract period, Party A will be responsible for any operating losses. During the contract period, all creditor's rights and debts will be handled by Party A by itself. If any losses to the company's property are caused, Party A shall bear the liability for compensation.

4. During the contract period, Party A enjoys full operational autonomy and personnel rights. The operating funds are raised by Party A by itself (the registered capital of the company is also handed over to Party A for operation). The operating personnel and all accounting personnel are hired or appointed by Party A. The wages and bonuses of the operating personnel are also paid by Party A but may be listed. into the company's operating expense account.

5. During the contract period, Party A must abide by the provisions of laws and administrative regulations, operate in accordance with the law, handle the company's annual inspection, submit accounting statements and pay taxes in accordance with the regulations and requirements of the industrial and commercial and tax authorities.

6. Within three days of this agreement taking effect, the contracting company’s official seal, special contract seal, special financial seal, bank account number and financial account books will be handed over to Party A in a list by both parties for confirmation by both parties.

7. Matters not covered in this agreement shall be resolved through negotiation between the two parties.

8. This agreement will come into effect after being signed and sealed by both parties.

9. If any dispute arises under this Agreement, it shall be subject to the jurisdiction of the court where Party A is located.

10. This agreement is made in two copies, with Party A each holding two copies.

Party A: Zhejiang Province __× Company Party B:

Legal representative: Legal representative:

Year, month, day, Hydropower Project Contracting Contract Chapter 5 < /p>

Contractor: _______________________

Legal representative: __________________

Position: __________________

Contractor: __________________

Legal representative: _______________

Position: _________________________

The two parties negotiated and signed this contract in accordance with _______________________.

1. Contract content: ______________________.

2. The contract period: starting from _________month_______ of _________year to _________month________ of _________year, ***_________ years.

3. Contracting form: ________________________________________.

(Incremental lump sum of profits turned over/incremental lump sum of after-tax contracting fees/contracting management responsibility system in which the total wages of employees are linked to the profits turned over, etc.)

4. Amount of profits turned over< /p>

1. The contractor shall use _________ yuan as the basis for turning over the profit lump sum. Starting from the _____________ year, the contractor will turn over the profits at an average annual increase rate of _________%, that is, in the year _________ it will be _________ yuan. , _________ year is _________ yuan, _________ year is _________ yuan.

2. All the remainder after turning over the profits will be left to the contractor, who will first repay the state loan and then establish a production development fund, incentive fund and employee welfare fund. The proportion of each fund is:

5. Contracting operation risk guarantee method

Risk mortgage or risk deposit guarantee. The contractor must submit a contracting operation risk deposit, letter of guarantee or risk deposit to the contracting enterprise before _________ day of _________month each year, in an amount of RMB________ yuan.

6. National mandatory product supply plan and production plan: ____________________________.

7. Main economic and technical indicators

1. The original value of fixed assets at the end of _____________ is _____________ million yuan, and the total value-added of fixed assets during the contract period is ___________ million yuan, of which _ _________year________yuan; _________year________yuan.

2. The maintenance of national assets is ________; the equipment integrity rate reaches ________%; the net value rate of fixed assets is ________%. Methods for disposal of idle assets___________.

3. New product development _________ item, the main new product is _________.

4. The total investment in technical transformation during the contract period is _________ yuan; in _________ year it is _________ yuan.

5. Product quality requirements____________________.

6. Main material and energy consumption indicators_______________.

7. Safety production and double guarantee indicators____________________.

8. Export foreign exchange earning index____________________________.

9. Output value indicator ____________________________.

10. The per capita profit turned in is ______________________.

8. Treatment of losses and/or debts of the enterprise before contract operation: ____________________________.

9. Rights and Obligations of Both Parties

(1) Contractor:

1. Should supervise the contracting enterprise to manage its assets in accordance with the provisions of the contract, and supervise The enterprise operates in accordance with the law, pays taxes in accordance with regulations, performs contracts, provides guidance, coordination, and service, and shall not interfere with the contractor's exercise of production management powers over the contracted enterprise;

2. Responsible for the approval and changes of this contract , cancellation and other approval and registration procedures;

3. During the contract period, the contracting party must respect the contractor’s autonomy and not interfere with the contractor’s normal business activities; and help the contractor solve the following problems: ________;

4. If the contractor fails to turn over ________% of the profit within the _________time due to poor management and management, or operates seriously illegally, or _________, the contractor may, after verification in conjunction with the relevant departments, Terminate the contract or change the operator in accordance with legal procedures.

(2) Contractor:

1. During the contract period, the contractor has the right to assume full responsibility for the production and operation management of the enterprise within the scope permitted by national laws and regulations, and exercise All production and operation management powers;

2. Must abide by national laws, regulations and financial accounting systems, strictly implement this contract operation contract, accept the supervision of the board of directors of the contracted enterprise, and comply with the provisions of laws and regulations , to protect the legitimate rights and interests of employees;

3. The legal person status, name and business scope of the enterprise shall not be changed during the contracting period. If changes are really necessary, they shall be approved by the board of directors of the contractor and reported to the original approval agency for approval; < /p>

4. No right to exercise any form of disposal power over the property of the contracted enterprise, such as transfer, sale, transfer, mortgage, pledge, lease, gift, etc.;

5. Contracted operation During this period, if a loan is made in the name of the contracted enterprise, it must be approved by the board of directors of the contracting party;

6. Income tax shall be paid on the contracting income in accordance with the law;

7. In accordance with national laws, policies, Within the scope permitted by the plan, the contractor has the right to establish a production and operation management system headed by the operator.

10. Rewards and Punishments for Business Operators

When the contractor fails to meet the contracting quota, the business operators will be punished according to the following circumstances: _________.

When the contractor completes or exceeds the contracting quota, the enterprise operator will be rewarded according to the following circumstances: _________.

11. The method of handling and assuming responsibility for disputes arising from the execution of the contract during the contract operation period with other companies, enterprises, individuals, etc.: _________.

12. When the contract operation period is suspended or the contract period expires:

1. The contracted enterprise shall conduct asset liquidation and capital verification, and the asset liquidation and capital verification shall be verified by a Chinese certified public accountant;

2. Principles of asset clearance and capital verification: _________;

3. Valuation method: _________;

4. Transfer procedure: _________.

13. Liability for breach of contract:

1. If the contracting party unreasonably interferes with the contractor's production and operation activities and causes losses to the contractor, the amount of compensation shall be deducted from the profits turned over. Compensation is calculated using ________.

2. If the contracting party fails to solve the _________ problem for the contractor in accordance with Article _____ of the contract, it shall pay liquidated damages at _____% of _____, and the liquidated damages shall be deducted from the profits handed over. .

3. If the contractor fails to turn over the total profit or annual profit according to the contract, it shall pay liquidated damages _________ according to the following method.

4. If the contractor fails to achieve the economic and technical indicators stipulated in Article ___________, it shall pay liquidated damages according to the following methods; if the enterprise upgrade is not achieved, __________; if the new fixed assets do not reach the specified amount When, ________; when the technical transformation task is not completed, ________; when product quality does not meet the required standards, ________.

5. If the contractor causes damage to the property of the enterprise during the contract period, compensation shall be paid according to the following methods: _________.

14. This contract must be approved by the original approval agency of the contracted enterprise before it can take effect. Changes, extensions, suspensions, and terminations of this contract must also be approved by the original approval agency. Within thirty days from the approval by the examination and approval authority, ________ shall go to the registration authority to complete the registration procedures.

15. The calculation of the contracted operation period begins on the date when the registration authority issues the registration certificate. The procedures for changes and deregistration of contracted operations shall be handled in accordance with the regulations of the registration authority, and both parties to the contract shall provide necessary assistance.

16. Statement and Warranty

(1) Contract issuing party:

1. The contract issuing party is an enterprise established in accordance with the law and existing legally, and has the right to sign and have the ability to perform this contract.

2. All formalities required for the contract issuing party to sign and perform this contract _________ have been completed and are legal and valid.

3. At the time of signing this contract, no court, arbitration institution, administrative agency or regulatory agency has made any judgment, ruling, award or specific administrative decision that would have a significant adverse impact on the contract-giver's performance of this contract. Behavior.

4. The internal authorization procedures required by the contract issuing party to sign this contract have been completed. The signer of this contract is the legal representative or authorized representative of the contract issuing party. This contract will be legally binding on both parties after it takes effect.

(2) Contractor:

1. The contractor is an enterprise established in accordance with the law and existing legally, and has the right to sign and the ability to perform this contract.

2. All formalities required for the contractor to sign and perform this contract _________ have been completed and are legal and valid.

3. When signing this contract, no court, arbitration institution, administrative agency or regulatory agency has made any judgment, ruling, award or specific administrative decision that would have a significant adverse impact on the contractor's performance of this contract. Behavior.

4. The contractor’s internal authorization procedures required to sign this contract have been completed. The signer of this contract is the contractor’s legal representative or authorized representative. This contract will be legally binding on both parties after it takes effect.

17. Confidentiality

Both parties promise to keep confidential the business secrets (technical information, operating information and other business secrets) obtained from the other party and cannot be obtained from public channels. A party shall not disclose all or part of a trade secret to any third party without the consent of the original provider of the trade secret. Except where otherwise provided by laws and regulations or otherwise agreed upon by both parties. The confidentiality period is ___ years

If a party violates the above confidentiality obligations, it shall bear the corresponding liability for breach of contract and compensate for the losses caused thereby.

18. Force Majeure

The term force majeure in this contract refers to objective events that cannot be foreseen, cannot be overcome, cannot be avoided, and have a significant impact on one party, including but not limited to natural disasters. Such as floods, earthquakes, fires and storms, as well as social events such as wars, unrest, government actions, etc.

If the contract cannot be performed due to the occurrence of a force majeure event, the party experiencing the force majeure shall immediately notify the other party in writing of the accident and shall provide details of the accident and the reasons why the contract cannot be performed or needs to be performed within _________ days. Written information on postponement of performance. After both parties agree, negotiate to terminate the contract or temporarily postpone the performance of the contract.

19. Notices

1. All notices that need to be issued according to this contract, as well as document exchanges between the parties, and notices and requirements related to this contract, must be in writing, and can be Delivery by ________ (letter, fax, telegram, delivery in person, etc.). If the above methods cannot be delivered, the method of delivery can be adopted.

2. The correspondence addresses of all parties are as follows: ____________________________________________.

3. If one party changes its notice or mailing address, it shall notify the other party in writing within ______ days from the date of change; otherwise, the party that has not notified shall bear the corresponding liabilities arising therefrom.

20. Handling of Disputes

(1) This contract shall be governed by and interpreted in accordance with the laws of _________ country.

(2) Disputes arising during the performance of this contract shall be resolved through negotiation between the parties, or may be mediated by the relevant departments; if negotiation or mediation fails, the dispute shall be resolved in accordance with the following _________ method:

p>

1. Submit to _________ Arbitration Commission for arbitration;

2. File a lawsuit in the People's Court in accordance with the law.

21. Interpretation

The understanding and interpretation of this contract shall be based on the purpose of the contract and the original meaning of the text. The title of this contract is only for the convenience of reading and shall not affect the Interpretation of this Contract.

22. Supplements and Attachments

Matters not covered in this contract shall be implemented in accordance with relevant laws and regulations. If laws and regulations are not provided for, both parties may reach a written supplementary agreement. The attachments and supplementary agreements to this contract are integral parts of this contract and have the same legal effect as this contract.

23. Contract validity

This contract shall take effect from the date when both parties or their legal representatives or their authorized representatives sign and affix their official seals. The validity period is ____________ year, from _________month________day of _________year to _________month________day of _________year. The original of this contract is made in _________ copies, each party holds _________ copies, which have the same legal effect; there are _________ copies of the contract, and one copy shall be sent to _________ for retention.

Contractor (seal): __________________ Contractor (seal): __________

Legal representative (signature): _____________ Legal representative (signature): ______

_________year________month______day________year______month______day

Signing place: ____________________ Signing place: ______________