202 1 Standard Edition of Construction Contract 1 Party A (General Contractor): _ _ _ _ _ _ _ _ _ _ _
Party B (subcontractor): _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws, regulations and rules, Party A contracts out the manual, mechanical and surveying works of the landscape wall of Dafangli to Party B. In order to clarify the rights and obligations of both parties, the two parties reached the following agreement through consultation on the principle of voluntariness and good faith for common compliance.
I. Overview of the Project
Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;
Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;
Construction scale: _ _ _ _ _ _ _ _ _ _ _ _.
Second, the way of contracting.
The comprehensive unit price does not include materials;
Three. Scope of contract
① Complete all carpentry, bricklayer, bricklayer, steel bar worker, scaffolder and painter required for the landscape wall. (including scaffold erection and dismantling, concrete formwork fabrication and dismantling).
(2) The equipment, machinery, tools and materials used in this project are unloaded at the site, and the site materials are transported for the second time. (Including generators, mixers, etc. )
(3) The cost of water and electricity used in this project.
The comprehensive unit price shall also include the following work contents or expenses:
1, the first floor, reinforced concrete structure; Exterior wall awning removal, outdoor aproll stepping, parapet benzene board, parapet reinforcement production and binding, formwork installation and removal and installation along the line, roofing leveling layer plastering, thermal insulation benzene board laying, artificial backfill soil, earthwork tamping, decoration shelf erection, exterior wall shelf removal and downspout installation; Parapet masonry, external wall brick pasting, plastering, internal network, indoor floor, concrete pouring and leveling.
2. Equipment, machinery, tools and unloading in the site are used for the project, and materials in the site are transported for the second time.
3, site safety production, civilized construction, fence, overlay facilities, labor costs;
4, the main decoration, various types of work, chefs and required mechanical operators (except tower crane drivers) and other labor costs.
Fourth, the contract price.
This project is contracted in the form of comprehensive unit price per linear meter, and the quoted unit price is guaranteed at one time.
1, comprehensive price: _ _ _ yuan/meter.
2. Party B's material losses are within the specified range; The expenses for intentionally wasting materials shall be borne by Party B.
Verb (abbreviation of verb) settlement and payment method
1. The total progress of this project is _ _ _%. After completing _ _ _% of the total contract price, Party A will pay _ _ _ _% of the image output value.
2. After all the projects contracted by Party B are completed, Party A shall pay _ _ _ _% of the total output value, and the remaining _ _ _ _% shall be reserved as warranty money, which shall be paid in one lump sum after the two-year warranty period of the decoration project expires.
4. For the construction contents agreed in this contract, if Party A actually has projects that do not need Party B's construction, Party A shall notify Party B in time and deduct the project cost at the time of project settlement.
5. The project payment shall be paid by Party A to Party B in the form of cash or check, and Party B shall provide the workers' payroll and the invoice of the subcontracting manual, otherwise Party A has the right to refuse to pay.
VI. Term of the Contract
This project started on _ _ _ _ _ _ _ _ _ _ _.
Seven, quality requirements
1. Quality standard: qualified upon completion and acceptance.
2. Project quality: According to the quality agreement in the general contracting contract, the current national construction grade acceptance specifications and quality evaluation standards for construction and installation projects must reach the quality evaluation grade. Any fine imposed by the quality supervision department or the construction unit or supervision unit due to the project quality shall be borne by Party B. ..
3. In case of quality defects during construction, Party B shall eliminate them in time, and the resulting construction period and material losses shall be borne by Party B; If the engineering defects caused by Party B are not eliminated in time, Party A has the right to eliminate the engineering defects by itself or by entrusting a third party, and the expenses arising therefrom shall be borne by Party B, who shall bear the corresponding liabilities for breach of contract.
Eight. Responsibilities and rights of Party A
1. Appoint Comrade as the project site construction manager to coordinate and guide the construction in a unified way.
2. Set up a project management team suitable for the project, fully perform the general contract, organize the implementation of construction management, and be responsible to the owner for the construction period and quality of the project;
3, responsible for the preparation of construction organization design, unified management objectives, organize the preparation of monthly construction plans, and control, supervise, inspect and accept the project quality, time limit for a project, safe production, civilized construction, measurement and test;
4. Be responsible for engineering survey and positioning, settlement observation, technical disclosure, organization of the blue prints.the design, unified arrangement of technical file collection and completion acceptance;
5. Coordinate and solve the water and electricity consumption of temporary production and living facilities, work and construction site that Party B does not use independently;
6, provide drawings on time, timely delivery of materials and equipment, fuel, turnover materials and safety facilities provided by construction machinery and equipment to ensure the construction needs. Tower crane drivers have to work at 4 am and 6 pm.
7. Pay labor remuneration to Party B according to the stipulations of this contract;
8, responsible for contact with the owner, supervision, design and related departments, coordinate the working relationship.
Nine. Responsibilities and rights of Party B
1. Designate a comrade as the person in charge of site construction, attend the project production coordination meeting, and be responsible for the construction management of this project.
2. Be responsible to Party A (the project contractor) for the project quality within the subcontracting scope of this contract, organize skilled workers with corresponding qualification certificates to take up their posts, and shall not employ mental patients, patients with infectious diseases, people over 50 years old and child workers who are not suitable for this job; Without the authorization or permission of Party A, it is not allowed to establish working contact with the construction unit and relevant departments without authorization; Consciously abide by laws and regulations and relevant rules and regulations;
3. Carefully organize the construction in strict accordance with the design drawings, construction acceptance specifications, relevant technical requirements and construction organization design to ensure that the project quality meets the agreed standards; Scientifically arrange the operation plan and invest enough manpower and material resources to ensure the construction period; Strengthen safety education, conscientiously implement safety technical specifications, strictly abide by the safety system, and implement safety measures to ensure construction safety; Strengthen site management, strictly implement the management of the construction site by the competent construction department and relevant departments of environmental protection, fire protection and health, and achieve civilized construction; Bear the losses caused by its own responsibility, such as quality modification, rework, construction delay, safety accidents, property losses, messy scene and various fines;
4. Consciously accept the management, supervision and inspection of Party A and relevant departments; Accept Party A's inspection of the storage and use of its equipment and materials and the valid certificates and certificates of its operators at any time; Coordinate with other units on site and take the overall situation into consideration;
5. Do a good job in the protection of finished products of buildings, structures, underground pipelines and completed projects around the construction site. If the damage is caused by Party B's responsibility, Party B shall bear all economic losses and various fines caused thereby;
6. Party B must obey the instructions of the construction unit and supervision engineer issued by Party A. ..
7. Party B is strictly forbidden to subcontract the project. If Party B subcontracts the project, Party A has the right to terminate this contract unilaterally, and all the consequences and losses caused thereby shall be borne by Party B itself, and Party A shall be paid a penalty of _ _ _ _ _% of the contract price.
8. Relevant expenses stipulated by government departments shall be borne by Party B, and Party B shall be responsible for providing copies of corresponding qualifications, licenses and safety production licenses (originals for future reference).
9. When Party A pays Party B's wages, Party B shall report to Party A the total wages of workers. ..
10. Unless otherwise agreed in this contract, Party B shall be responsible for the implementation and completion of its operation contents, and Party B shall undertake and perform all obligations and work procedures related to labor operation agreed in the general contracting contract.
1 1. In the construction project of Party B, if personal and property losses are caused to itself or others due to Party B's reasons, Party B shall be liable for compensation.
12. Party B shall be qualified to engage in the projects agreed in this contract. If Party B does not have the corresponding qualifications and conditions, Party B shall pay _ _ _% of the contract price to Party A as liquidated damages and bear all legal consequences.
Ten, engineering materials, turnover materials, instruments, machinery and equipment.
1. All materials, semi-finished products and finished products required for this project are supplied to the site by Party A, and Party B shall assist Party A in managing and keeping all kinds of materials on site, and Party A has the right to require Party B to compensate for the waste;
2. Party B shall designate a special person to collect Party A's tools, instruments and turnover materials, and keep them properly and use them reasonably after receiving them. After use, the number should be restored as it is in time. In case of loss or damage, in addition to normal losses, compensation shall be made according to the purchase price of Party A..
3. Party A is responsible for providing large, medium and small mechanical equipment according to the needs of the project, and ensuring mechanical equipment and spare parts, fuel, hydraulic oil and butter. And ensure the quality of mechanical equipment, to ensure that the intact rate reached _ _ _ _%. Party B is responsible for the use and maintenance. If the mechanical equipment is damaged due to Party B's improper use, the expenses incurred in repairing and purchasing accessories will be deducted from the project settlement. After the project is completed, Party A will accept that the intact rate of machinery and equipment is _ _ _ _%. If the machinery cannot be used normally, Party A will deduct it from the project payment paid to Party B according to the degree of losses caused.
4. If it is lost or damaged due to improper storage and use by Party B, Party B shall not only compensate, but also bear all economic losses caused by the delay in the construction period.
XI。 Safe production, civilized construction and labor protection
1. Party B shall abide by the management regulations on production safety in engineering construction, carry out construction in strict accordance with safety standards, and accept the supervision and inspection carried out by industry safety inspectors according to law at any time, and take necessary safety protection measures to eliminate hidden dangers of accidents. For accidents and expenses caused by Party B's ineffective safety measures or violation of safety operation rules, Party B shall bear all legal responsibilities and all economic losses caused thereby.
2. Party B has the right to criticize and suggest the working conditions on the construction site and the potential safety hazards in the construction process, and has the right to refuse illegal command and risky operation; Party A shall not require Party B to carry out construction in violation of safety management regulations, and Party A shall bear corresponding responsibilities and expenses for safety accidents caused by Party A's reasons. ..
3. In case of safety accidents such as casualties, Party B shall immediately notify Party A and take necessary measures, and the expenses and responsibilities arising therefrom shall be borne by the responsible party; If the responsibility for the accident is not clear, it shall be handled in accordance with relevant regulations. The government supervision department or supervision department of the project can be entrusted to investigate the accident responsibility, and the final conclusion can be recognized by both parties.
4. Party A must take out accidental injury insurance for employees engaged in dangerous operations, and take out insurance for the life and property of their personnel on the construction site and construction machinery and equipment, and pay the insurance premium.
5. Civilized construction: Party B shall pile up materials, machines and tools according to Party A's unified planning, set up signs according to Party A's standardized site requirements, assign special personnel to manage the hygiene of living quarters and work areas, and do a good job in public security in its own responsibility area; Party B must obey the management, keep the site clean and tidy, and keep the raw materials neatly stacked. The machinery used should be cleaned and maintained in time. If the inspection does not meet the requirements, Party B will pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
6. When the project is completed, Party B is responsible for removing all kinds of obstacles caused by the construction on the construction site, so as to clean up the site after the project is completed.
7. Without permission, it is forbidden for female workers and their families to live on the site. In case of violation of this Agreement, Party B shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
8. No one is allowed to make trouble or fight at the construction site, and offenders will be expelled. If serious consequences are caused, it will be transferred to judicial organs for investigation according to law, and Party A has the right to terminate the performance of this Labor Contract.
9. Party B requires uniform safety helmet for on-site clothing (work clothes) (Party A shall guide the procurement in a unified way, and the expenses shall be borne by Party B, which will not be returned after the project is completed).
Twelve. responsibility for breach of contract
1. If the construction period is delayed due to Party A's reasons, the construction period may be postponed, and Party A shall pay Party B the loss of extended working hours. If the project cannot be completed within the specified time limit due to Party B's reasons, the penalty for each day of delay is _ _ _ _ _ _ _ _ _ _ _.
2. If Party B's construction quality fails to meet the quality standards agreed in this contract, but it can meet the minimum standards stipulated by the state, or the engineering defects caused by Party B are not eliminated in time, Party B shall pay liquidated damages of _ _ _% of the contract amount to Party A, and meet the engineering quality requirements or relevant standards agreed in this contract within the time limit specified by Party A. ..
3. If Party B fails to perform or perform other obligations under this contract as agreed, the losses caused shall be borne by the responsible party (Party B shall pay in advance), and Party A shall be paid a penalty of 1% of the contract amount. Party B shall also compensate Party A for the economic losses caused by its breach of contract, and the working hours delayed by Party B shall not be postponed.
4. In the process of construction, if Party B disobeys the on-site command and the construction period and quality defects still fail to meet the requirements after rectification, Party A may order Party B to quit the construction site and change the construction team. Party B must leave the site unconditionally, and Party A shall pay _ _ _ _% of the completed project.
5. If Party A finds that Party B wastes materials in the construction process, it will compensate twice the amount of wasted materials, and Party B shall also bear the penalty of RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
6. After Party B breaches the contract, when Party B requests the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after assuming the above liabilities for breach of contract.
Thirteen. special agreement
1. If there is a debt dispute caused by Party B's default in the labor cost of the project, and Party A has paid or may pay the above-mentioned money to a third party, Party A has the right to pay the above-mentioned money with the project money paid by the construction unit or in kind instead of the project money or the collateral provided by Party B. In case of insufficient above-mentioned money, Party B shall bear the losses and corresponding legal responsibilities;
2. All kinds of on-site recognition of this project only represent the actual facts, and the settlement is no longer carried out separately, and the comprehensive unit price has included its work content.
Fourteen Dispute mediation
Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, it shall be submitted to the people's court of _ _ _ _ _ _ _ _ _ _.
Fifteen. Termination of contract
1. If Party B fails to pay the labor remuneration as agreed in this contract, Party B may stop working. If Party A fails to pay the labor remuneration within one week, Party B may terminate the contract by giving a notice.
2. If the general contracting or professional subcontracting contract is terminated before Party B fully performs its obligations under this contract, Party A shall notify Party B to terminate this contract. When Party B withdraws from the site within 7 working days after receiving the notice, Party A shall pay Party B the labor remuneration for the completed project.
3. If this contract cannot be performed due to force majeure, or the project is suspended or postponed due to one party's breach of contract or the reason of the construction unit, both parties may terminate the contract.
4. After the termination of the contract, Party B shall properly protect and hand over the completed project and the remaining materials and equipment, and evacuate the construction site according to Party A's requirements ... Party A shall provide necessary conditions for Party B's evacuation, pay the above expenses, and pay the labor remuneration for the completed work as agreed in the contract. The party at fault shall compensate the other party for the losses caused by the termination of the contract. After the termination of the contract, the validity of the settlement and liquidation clauses agreed by both parties in the contract will not be affected.
Sixteen. Termination of contract
After both parties have fulfilled all their obligations under this contract and paid labor remuneration, Party B will deliver the labor operation results to Party A, and this contract will be terminated after Party A's acceptance. Party B shall not default on the wages of workers, and if it breaches the contract, the consequences shall be borne by Party B..
Seventeen. Other agreements
Party B shall provide valid certificates and labor manual invoices related to the qualification of the labor service company, otherwise Party A has the right to refuse to pay. Matters not covered in this contract shall be settled by both parties through consultation. This agreement is made in duplicate, one for each party. This agreement shall come into force after being signed and sealed by both parties.
Signature of Party A: _ _ _ _ _ _ _ _ _ _ Signature of Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
202 1 Employer of the Second Edition of Construction Contract Standard: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _, hereinafter referred to as Party A.
Construction party: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _, hereinafter referred to as Party B.
Party A needs to add two floors to the original floor so that Party B can contract the construction. In order to complete the project with good quality and quantity, both parties have reached the following agreement through consultation:
1. Party A supplies raw materials, Party B is responsible for the whole project construction from the main body to the decoration, and Party B listens to Party A's opinions in design.
2. Calculated according to the construction area, the unit price is _ _ _ _ _ _ _ _ _ yuan per square meter, which shall be paid to Party B (including water and electricity installation).
Three. Quality requirements: the vertical error of the main floor should be within 2 cm, but not more than 2 cm. Mortar should be full, and decoration plastering should be intermediate. The deviation shall be firmly bonded according to the construction specifications, and the surface shall be free of ash explosion, cracks, floor tiles, hollowing, skew, lack of rafters and corners. Other decoration shall conform to the construction specifications.
Four, the main structural requirements, board gluten fabric _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. During the construction period, Party B shall provide safety protection facilities to ensure safety first and quality first. In case of personal injury or third party casualties during the construction period, Party B shall be responsible for all the consequences, and Party A shall not bear any responsibility.
6. Payment method: Party B asks for payment in the middle of construction, and both parties negotiate to pay, and pay in one lump sum after the project is fully completed and accepted.
Seven. This agreement is made in duplicate, one for each party. I hope that both parties will jointly implement it.
Signature of Party A: _ _ _ _ _ _ _ _ _ _ Signature of Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
202 1 Construction Contract Standard Version 3 Party A (full name): _ _ _ _ _ _ _ _ _ _ _ (Employer)
Party B (full name): _ _ _ _ _ _ _ _ _ _ (contractor)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction project of this construction project and conclude this contract.
I. Overview of the Project
Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Project location: _ _ _ _ _ _ _ _ _ _ _ _.
Scope of work: Carry out construction according to the requirements of Party A's engineering department. Project content and price:
Second, the contract period
Commencement date: Completion date: before.
Third, the quality standard
1, the engineering quality is based on the national or industrial quality inspection and evaluation standards. If the project quality fails to meet the agreed quality standards due to Party B's reasons, Party B shall be liable for breach of contract.
2. Party B shall carry out the construction in strict accordance with the requirements of standards, specifications and design drawings and the instructions issued by Party A according to the contract, and accept the inspection of Party A at any time to provide convenient conditions for inspection and inspection.
3. If the project quality does not meet the agreed standards, Party A has the right to require Party B to demolish and rebuild until it meets the agreed standards. If the agreed standards cannot be reached due to Party B's reasons, Party B shall bear the costs of demolition and reconstruction, and the construction period will not be postponed.
Fourth, quality warranty.
1, and the quality warranty period is _ _ _ _ _ _ years, counting from the date when the project is completed and accepted. Maintenance during the warranty period is free. If there is any quality problem, Party B shall guarantee to repair it within 48 hours after Party A's notice, otherwise Party A may hire someone to repair it, and the expenses incurred shall be deducted from the warranty fund. If the warranty money is insufficient, Party A may claim compensation from Party B. ..
2. Party B shall be responsible for the quality warranty of the project delivered to Party A within the quality warranty period according to laws, administrative regulations or national regulations on the quality warranty of the project.
3. The quality deposit is calculated at _ _ _ _% of the project cost, deducted from the project payment, and paid after the warranty period expires.
5. Contract price and payment: after completion, the project price listed in Article 1 of this contract is a comprehensive unit price, including main and auxiliary materials, labor, transportation, management fees, taxes, all risk responsibilities and all possible expenses stipulated in the policy documents.
Payment method: 95% of the final settlement price shall be paid within 30 days after the project is completed and accepted. For each payment, Party B shall provide a payment slip signed by the heads of Party A's engineering department, finance department and other relevant departments and a formal and effective tax invoice.
Liability for breach of contract of intransitive verbs
1. Party B promises to Party A to carry out construction and completion according to the contract. If Party B fails to complete the project according to the completion date agreed in this agreement or the extended period with the written consent of Party A due to Party B's reasons, Party B shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. If the quality of the project fails to meet the quality standards agreed in this agreement due to Party B's reasons, Party B shall bear the liability for breach of contract and compensate Party A for the losses caused by its breach of contract.
3. When one party breaches the contract and the other party requests the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after assuming the above liabilities for breach of contract.
Seven. Construction safety: Party B shall abide by the management regulations on production safety in engineering construction, organize the construction in strict accordance with safety standards, take necessary safety protection measures to eliminate hidden dangers of accidents, and take full responsibility for quality problems and safety accidents in the construction process and the expenses arising therefrom.
Eight. Party A promises to Party B to pay the contract price and other payables according to the time limit and method agreed in this contract.
Nine. Party B's domicile is the official and valid address. Any notice or other legal documents sent by Party A to Party B shall be delivered to the agreed residence by registered mail, and shall be deemed to have been received by Party B three days after the mailing time, and the mailing time shall be subject to the postmark time.
Nine. This agreement is made in duplicate, one for each party, and shall come into force after being signed and sealed by both parties, and both parties shall abide by it.
X other agreements: before the project is accepted and delivered to party a, party b shall be responsible for cleaning up the garbage in time.
Signature of Party A: _ _ _ _ _ _ _ _ _ _ Signature of Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
202 1 Standard Version 4 of Construction Contract Party A: _ _ _ _ _ _ _ _ _ _ (Employer)
Party B: _ _ _ _ _ _ _ _ _ _ (contractor)
In order to clarify the responsibilities and complete the task on time, with good quality and quantity, according to the Economic Contract Law of the People's Republic of China and relevant national laws, regulations and policies, combined with the specific conditions of this project, the following terms are signed by both parties through consultation, which * * * will abide by jointly.
Article 1: Project Overview
I. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Three. Project scope and information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Four. Total project cost: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Verb (abbreviation of verb) quality grade: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Construction period of intransitive verbs: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2: Contract method
This project is contracted in the following ways.
1, according to the construction drawing budget plus visa, plus policy adjustment settlement;
2, the contractor does not package materials;
3. Contracting projects and materials.
If the lump sum contract is adopted, it will generally not be adjusted. However, in case of price adjustment of equipment and materials and irresistible natural disasters caused by design change or policy adjustment, the contract project price can be adjusted.
Article 3: Payment and Settlement of Price
1. Payment method of project funds: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Two, due to engineering design changes caused by the increase or decrease of quantities, the increase or decrease price according to the relevant quota, according to the actual settlement.
Three. Engineering settlement basis
Article 4: Engineering Changes
During the construction of this project, either party shall not change the design at will. If it is really necessary to change, the visa agreement can only be changed after consultation between both parties.
Article 5: Project Acceptance
A, after the completion of the project, the two sides organize relevant personnel to timely acceptance.
2. After the project is completed and accepted, Party A can use the project. Without acceptance, it is regarded as a qualified project.
Article 6: Warranty Conditions and Duration
The warranty period is one month. During the specified warranty period, all quality accidents and quality defects caused by construction shall be guaranteed by Party B free of charge (due to improper use and man-made damage by Party A, it is not within the free warranty scope).
Article 7: Obligations of both parties
Party A:
1. Before the project starts, provide Party B with copies of construction drawings and geological survey reports, and organize the original design unit to conduct technical disclosure and blue prints.the design to Party B. ..
Two, do a good job in the construction area of "three links and one leveling" (water, electricity, roads, site leveling) and the original underground pipelines, circuits and other obstacles cleaning and relocation.
Three. Ensure Party B's working and living environment during the construction period, and assist Party B in coordinating local mass relations.
Party B:
A, responsible for the construction site layout, specify the power supply, water, roads and materials piled up;
Second, according to the construction project documents, drawings, materials and relevant regulations brought by Party A according to the contract, prepare the construction plan in time and make good preparations for construction;
Three, in strict accordance with the construction drawings and technical specifications for construction, to ensure the quality of the project. According to the time stipulated in the contract, the project will be completed and delivered for acceptance as scheduled. In case of force majeure, the contract period will be postponed.
Article 8: Liability for breach of contract
Party B's responsibilities:
A, the project quality does not conform to the provisions of the contract, responsible for free repair or rework. If the delivery is delayed due to repair or rework, the overdue penalty shall be paid.
2. If the project is not delivered within the time limit stipulated in the contract, a penalty of 1/10000 of the project cost shall be paid for every 65,438+0 days overdue.
Party A's responsibilities:
1. If it fails to perform its due obligations as stipulated in the contract, it shall compensate for the actual losses caused to Party B in addition to delaying the completion date;
Two, due to design changes and design errors caused by the project stop, delay or rework, measures should be taken to make up for or reduce losses. At the same time, compensate Party B for the actual losses caused by shutdown, slowdown, rework, transshipment, relocation of personnel and mechanical equipment, and overstock of materials and components;
3. Party A shall be responsible for the quality or other problems arising from the use of the project or unauthorized use of the project before acceptance;
4. If Party B fails to accept the bid-winning notice within 3 days, it shall pay overdue liquidated damages as required;
5. If the project funds are not allocated as stipulated in the contract, Party B shall be paid one ten thousandth of the compensation per day according to the deferred payment amount stipulated by the bank in the overdue payment method.
Article 9: Safe and civilized construction
Party B shall take strict safety protection measures in accordance with relevant regulations, and bear the responsibility for accidents caused by its own ineffective safety measures and the expenses arising therefrom. In case of casualties not caused by Party B, the responsible party shall bear the responsibilities and related expenses.
Party B shall conduct civilized construction, strengthen the management of the construction site, and ensure the smooth progress of the construction.
Article 10: supplementary provisions
1. The modification of building facilities change documents, negotiation records, meeting minutes and data charts agreed by both parties through consultation is also an integral part of this contract;
2. Party A is appointed as the on-site representative; Party B is designated as the on-site representative.
Three. Matters not covered in this contract shall be settled separately by both parties.
Four. This Contract is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Signature of Party A: _ _ _ _ _ _ _ _ _ _ Signature of Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.