Employer (Party A):

Contractor (Party B):

Same serial number:

Tianjin Administration for Industry and Commerce

Producer of Tianjin Construction Management Committee

Use it to explain.

1. The text of this contract is applicable to the residential decoration project within the administrative area of this Municipality. The applicable period of this version of the contract text is before the release of the new version of the contract text.

2. The project contractor (Party A) shall be the owner or lessee of the property. The project contractor (Party B) shall have a business license issued by the administrative department for industry and commerce and a construction enterprise qualification certificate issued by the administrative department for construction.

3. If Party A and Party B directly sign this contract, this contract is made in duplicate, with each party holding one copy; This contract is signed in various markets in this city, and the market organizer is willing to provide guarantee for the contractor's performance responsibility and warranty responsibility, in triplicate (Party A and Party B and the market organizer each hold one copy).

4. Commencement: After both parties complete the design scheme, the first phase of the project payment is in place, and the technical disclosure of the project, the materials and construction personnel arrive at the construction site to start operations.

5. Completion: All the project contents (including indoor air quality inspection) agreed in the contract are completed, and it will be deemed as completion after the contractor, the supervision unit and the employer pass the acceptance.

6. Acceptance: The contractor, the supervision unit and the employer sign and seal the project completion acceptance form, or those who have not gone through the acceptance formalities but the employer has moved in and used it are deemed as qualified.

7. Extension of construction period: refers to the extension of construction period after the project progress is affected by reasons other than Party B's ... If the construction period is postponed, Party B will not be liable for breach of contract.

Stamping office

Terms of Tianjin Residential Decoration Project Construction Contract

Employer (hereinafter referred to as Party A):

Authorized Agent (Name): Nationality:

Address: ID number:

Phone: Mobile phone number:

Contractor (hereinafter referred to as Party B):

Address: Business License Number:

Legal Representative: Tel:

Authorized Agent: Tel:

Building qualification grade certificate number:

Designer of this project: Tel:

Person in charge of construction team: Tel:

Guarantor: (market organizer)

Legal Representative: Authorized Agent: Tel:

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Regulations of Tianjin Municipality on the Protection of Consumers' Rights and Interests and other relevant laws and regulations, combined with the characteristics of residential decoration in this city, on the basis of equality, voluntariness and consensus, Party A and Party B have reached the following agreement on matters related to Party B's contracting of Party A's family room decoration project (hereinafter referred to as the project):

Article 1 General situation of the project

1. 1 Project location:

1.2 engineering decoration area:

1.3 project unit type:

1.4 project contents and practices (see project quotation (Annex I) and drawings (Annex VI));

1.5 project contracting, using the following methods:

(1) Party B contracts all materials (see Annex 3).

(2) Part of the materials are contracted by Party B, and the rest are provided by Party A (see Attached Tables 2 and 3).

1.6 Project duration (calculated according to actual working days);

Commencement date year month day;

Completion date year month day.

1.7 project payment and project quotation

(1) project cost: the project cost of this contract is (RMB).

Amount in words:

(2) The quotation is agreed by both parties in accordance with the operation rules of market economy and the principle of high quality and good price, and is an annex to this contract.

(3) The quotation sheet shall be compiled together with material quality standards and safety manufacturing technology as the basis for determining the project price.

Article 2 Project supervision

Where the project is supervised, Party A shall sign a project supervision contract with the project supervision company approved by the construction administrative department, and notify Party B of the name, unit, contact information and responsibilities of the supervision engineer.

Article 3 Construction drawing and pre-evaluation calculation of indoor environmental pollution control

3. 1 Construction drawings shall be provided as follows:

(1) If Party A designs by itself, it is required to provide the construction drawings and indoor environmental pollution control pre-evaluation calculation in triplicate, with Party A holding one copy and Party B holding two copies.

(2) Where Party A entrusts Party B with the design, Party B shall provide the construction drawings and indoor environmental pollution control pre-evaluation calculation in triplicate, one for Party A and two for Party B.. Construction drawings and indoor environmental pollution control, evaluation and calculation costs are included in the contract project costs.

3.2 The construction drawings and pre-evaluation calculation of indoor environmental pollution control provided by both parties must meet the requirements of Code for Indoor Environmental Pollution Control of Civil Building Engineering (GB50325-200 1).

3.3 Both parties shall sign the construction drawing and pre-evaluation calculation for indoor environmental pollution control.

3.4 Both parties shall not copy or transfer the construction drawings, design schemes and other materials provided by the other party to a third party without authorization, nor shall they be used for projects other than this contract.

Article 4 Work of Party A

4. 1 On the principle of not affecting the construction, create conditions for Party B to enter the site for construction three days before the commencement.

4.2 Free water supply, power supply and winter heating during construction.

4.3 Be responsible for the commencement formalities of the property management department and the related expenses that should be paid by the owner.

4.4 Comply with the regulations of the property management department.

4.5 Be responsible for coordinating the relationship between Party B's construction personnel and the neighborhood.

4.6 Party B shall not be forced to engage in any of the following acts:

(1) Change the main body and load-bearing structure of the house at will.

(2) Open doors and windows on the external wall or expand the size of the original doors and windows, and dismantle the wall connecting the balcony doors and windows.

(3) Pave stones more than one centimeter indoors, build walls, and increase the floor load.

(4) Destroy the waterproof layer of the kitchen and bathroom floor, and tear down the heating, heating, gas and other pipeline facilities.

(5) Other behaviors that force Party B to operate illegally.

4.7 If the contents listed in Article 4.6 need to be involved, Party A shall hold the approval documents of the housing management department.

4.8 During the construction period, if Party A still needs to use part of the living room, Party A has the responsibility to cooperate with Party B to do a good job in safety and fire control; Party A shall properly keep the articles left in the living room and explain the matters needing attention.

4.9 Participate in the supervision of project quality and construction progress, and participate in project data, concealed works and completion acceptance.

Article 5 Party B's Work

5. 1 During the construction process, the construction specifications, quality standards, safety operation procedures and fire prevention regulations shall be strictly implemented, and the project contents agreed in this contract shall be completed safely, with good quality and on schedule.

5.2 Strictly implement the regulations of the municipal construction administrative department on the management of the construction site:

(1) Without the approval procedures of the housing management department and the reinforcement drawings, the main building and load-bearing structure in the project shall not be demolished, the floor load shall not be increased, and the original indoor heating, heating, gas and other pipeline facilities shall not be changed.

(2) Do not disturb the people and pollute the environment. Do not engage in noisy decoration activities such as knocking, chiseling, planing and drilling from 12 to 14 and 18 to 8 o'clock the next day.

(3) Party B shall be responsible for the maintenance and compensation for the losses caused by pipeline blockage, water leakage, water cut-off and power failure of adjacent residents' houses due to decoration construction.

(4) Responsible for the protection of finished engineering products, equipment and living room furniture.

(5) Ensure that the plumbing in the room is unblocked and the bathroom is clean.

(6) Ensure the cleanliness of the construction site, and clean up the construction site after daily completion.

5.3 Provide Party A with the consulting conditions of various written materials such as standards, specifications, calculations and reference prices involved in the signing and performance of this contract by notifying the website and unified publicity.

5.4 If Party A is a minority, Party B shall respect its national customs and habits during the construction.

Article 6 Engineering changes

During the construction period, if it is necessary to change the project contents agreed in the contract, both parties shall reach an agreement through consultation. Both parties to the contract * * * sign a written change agreement, and at the same time adjust the related project cost and time limit for a project. Engineering change agreement, as the basis for completion settlement and extension of construction period.

Article 7 Material supply

7. 1 It shall be provided in the manner and contents agreed in the Schedule of Engineering Materials and Equipment Supplied by Party A (Annex II) and the Schedule of Engineering Materials and Equipment Supplied by Party B (Annex III) of this contract.

(1) For the materials and equipment to be provided by Party A, Party A shall notify Party B before the materials and equipment arrive at the construction site. Both parties shall check and accept the quality of materials and equipment and environmental protection standards, and handle the handover procedures.

(2) Before the materials and equipment provided by Party B arrive at the construction site, Party B shall notify Party A.. Both parties shall accept the quality of materials and equipment and environmental protection standards, which shall be confirmed by Party A for the record.

(3) The building decoration materials provided by both parties must conform to the Limits of Harmful Substances in Interior Decoration issued by the General Administration of Quality Supervision, Inspection and Quarantine, and have qualified test reports issued by professional testing institutions recognized by relevant administrative departments.

(4) If one party disagrees with the materials provided by the other party and needs to re-inspect, the inspection fee shall be paid in advance; If the materials are really unqualified after testing, the testing expenses shall be borne by the other party.

(5) After the materials and equipment provided by Party A are accepted by Party B and the handover procedures are confirmed, Party B shall be responsible for the storage and quality control in the construction process.

Article 8 Time limit for a project is delayed

8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed after being confirmed by Party A in writing:

(1) engineering quantity change or design change;

(2) Force majeure;

(3) Other circumstances in which Party A agrees to postpone the construction period.

8.2 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly:

(1) Party A fails to complete its responsible work as agreed in the contract, which affects the construction period;

(2) Party A fails to pay the project payment as agreed in the contract, which affects the normal construction;

(3) Other circumstances that delay the construction period due to Party A's responsibility.

8.3 If the project cannot be completed on schedule due to Party B's responsibility, the construction period will not be postponed; If the project cannot be completed and accepted as scheduled due to Party B's reasons, the construction period will not be postponed.

8.4 The "written agreement recognized by both parties" will be used as the basis for determining the responsibilities of both parties.

Article 9 Quality standards

9. 1 The indoor environmental pollution control of decoration shall strictly implement the standards in Code for Indoor Environmental Pollution Control of Civil Building Engineering (GB50325-200 1).

9.2 The construction quality of this project shall be implemented according to the following standards:

(1) Implementation of Tianjin Residential Decoration Engineering Standard (DB-29-35-2004).

9.3 At the time of completion and acceptance, if both parties dispute the project quality and indoor air quality, they shall apply for certification to a professional testing institution recognized by the relevant administrative department; The expenses related to the certification process shall be paid by the applicant in advance and finally borne by the responsible party.

Article 10 Project acceptance

10. 1 During the construction process, the project quality will be jointly accepted in the following stages:

(1) Material acceptance;

(2) Acceptance of concealed works;

(3) Completion acceptance.

10.2 After the completion of the project, Party B shall notify Party A for acceptance, and Party A shall organize acceptance within three days after receiving the completion acceptance notice. After the acceptance, both parties shall go through the handover procedures, settle the final payment, sign the warranty, and Party B shall submit to Party A the hydropower transformation drawings of its construction part. ..

10.3 Before the completion acceptance by both parties, Party B shall be responsible for protecting the safety of finished products and the project site.

10.4 If both parties fail to go through the acceptance formalities, Party A shall not move in. If Party A moves in without authorization, it will be deemed as qualified, and the losses caused thereby shall be borne by Party A. ..

10.5 If there are some minor problems in the project quality, indoor air quality and economy during the completion acceptance, both parties can sign the Agreement on Solving the Remaining Problems of Completion Acceptance through Consultation (as an annex to the Completion Acceptance Sheet) and then move in first.

10.6 the warranty period of this project is two years under normal use conditions, and the warranty period of the kitchen and bathroom anti-leakage project with waterproof requirements is five years from the date when both parties sign the project.

10.7 this project shall be handed over to party a within three days from the date of acceptance and signature by both parties, and party b shall clean up and evacuate the construction site.

Article 11 Method of payment for project funds

1 1. 1 After the contract comes into effect, Party A shall pay the project payment to Party B as agreed in the following table:

Payment times, payment time, payment proportion of project funds and payable amount

first time

second time

the third time

1 1.2 The progress of the project is more than half, that is, all the water and electricity pipelines in the project have been laid, the wall surface and top surface base have been completed according to the technical requirements, and the doors, windows and fine stubble products have been basically installed, which is the standard to define more than half of the project.

After the acceptance of the project, Party A will review the project statement submitted by Party B. If there is no objection within 30 days from the date of submission, it shall be deemed that Party A agrees to pay the final payment of the project to Party B..

1 1.4 Within 3 days after all project funds are settled, Party B shall issue a formal unified invoice to Party A, which shall be the proof of project funds settlement.

Article 12 Liability for breach of contract

12. 1 If one party fails to perform its contractual obligations as agreed and causes losses to the other party, it shall be liable for compensation; If you are punished for violating relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party.

12.2 if one party cannot continue to perform the contract, it shall notify the other party within two days, and the responsible party shall bear the losses caused by the termination of the contract; If the performance of this contract cannot be continued due to Party B's responsibility, Party A has the right to order Party B to quit the construction site unconditionally within two days, and Party B shall bear all losses.

12.3 If Party A fails to pay the second and third project funds within the time limit stipulated in the contract, it shall compensate Party B for the actual losses, and pay Party B a penalty of 2‰ of the delayed project funds for each day of delay (i.e. RMB Yuan/day of delay).

12.4 If the construction period is delayed due to Party B's responsibility, Party B shall compensate Party A for the actual losses, and Party B shall pay Party A a penalty of 2‰ of the contract project cost for each day of delay (i.e. RMB Yuan/day of delay).

12.5 If the engineering quality and indoor air quality are unqualified due to Party B's responsibility, Party B shall rework, repair, comprehensively treat and compensate according to the following agreement:

(1) Party B must completely rework and repair the unqualified parts of the project. If the delivery of the project is delayed due to rework, it shall be regarded as the delay of the project, compensate Party A for the actual losses, and pay the liquidated damages according to the standard of 12.4.

(2) If the indoor air quality is unqualified, Party B must comprehensively treat it. If the delivery of the project is delayed due to governance reasons, it shall be regarded as the delay of the project, compensate the actual losses of Party A, and pay the liquidated damages according to the standard of 12.4.

(3) If the indoor air quality is still not up to standard after treatment, it is really Party B's responsibility, and Party B shall return the project payment to Party A; If Party A is also responsible for the nonconformity after deducting the cost price of materials unrelated to the nonconformity provided by Party B, Party B may reduce the return ratio accordingly.

If there is no liquidated damages stipulated in this article, the breaching party shall pay% of the contract project price to the other party as liquidated damages.

Article 13 Dispute settlement methods

In case of any dispute arising from this contract, both parties shall settle it through negotiation or apply to the market organizer or consumer association for mediation. If negotiation or mediation fails, the following methods can be adopted:

1. Apply to the Arbitration Commission for arbitration.

2. Bring a lawsuit to the people's court.

Article 14 Supplementary Provisions

This contract shall come into effect after being signed (sealed) by both parties.

14.2 The project shall not be subcontracted or illegally subcontracted after the signing of this contract.

14.3 both parties may modify or supplement this contract in writing, but if the modification or supplement reduces or exempts Party B from the responsibilities under this contract, this contract shall still prevail.

14.4 if the performance of the contract is affected or losses are caused due to reasons not attributable to both parties, both parties shall settle them through consultation on the principle of fairness.

14.5 if the market organizer provides a guarantee for party b's performance responsibility and warranty responsibility, the guarantee shall be valid from the date of signing this contract to the expiration of the warranty period agreed in this contract. If Party B fails to fulfill its obligations under this contract, the market organizer shall bear the guarantee responsibility. If Party B withdraws from the market, the organizer has the right to recover from Party B after assuming the responsibility.

14.6 this contract will be automatically terminated upon completion of performance.

Article 15 Other agreed matters

Party A (signature): Party B (seal):

Legal representative:

Entrusted agent:

Year after year, month after month, year after year.

Guarantor (seal):

Legal representative:

Entrusted agent:

Contact telephone number:

date month year

Schedule 1

Engineering quotation

Number project unit price quantity total amount processing method and material description

Representative of Party A (signature and seal): Representative of Party B (signature and seal):

Remarks: Enterprises with large amount in this form can copy it as an annex to the contract.

Schedule II

List of engineering materials and equipment provided by Party A

Serial number material name unit variety specification quantity supply time supply acceptance place

Representative of Party A (signature and seal): Representative of Party B (signature and seal):

Remarks: The supplied materials and equipment must have the inspection report of the professional inspection unit recognized by the administrative department.

Schedule 3

List of engineering materials and equipment provided by Party B.

Serial number material name unit variety specification quantity supply time supply acceptance place

Representative of Party A (signature and seal): Representative of Party B (signature and seal):

Remarks: The supplied materials and equipment must have the inspection report of the professional inspection unit recognized by the administrative department.

Schedule IV

Project completion acceptance form

Acceptance time: year month day.

Project name:

Project location:

Signature (seal) of Party A's completion acceptance opinion:

Signature (seal) of supervision unit:

Signature (seal) of Party B:

Remarks: At the time of completion acceptance, there are still problems that will not affect the overall project quality. Both parties can negotiate to move in, but they must sign an agreement on the remaining problems after completion as the basis for solving the remaining problems after moving in.

Schedule 5

Residential engineering warranty

The first party

Telephone number of Party A's agent

party B

Telephone number of legal representative

Home improvement project address

Commencement date and completion date

The warranty period is from MM DD YY to MM DD YY.

Representative of Party A (signature and seal): Representative of Party B (signature and seal):

Remarks:

1. Since the date of completion acceptance, the warranty period for decoration is calculated as two years, and the warranty period for anti-leakage works in kitchens and bathrooms with waterproof requirements is five years;

2. During the warranty period, Party B shall promptly and unconditionally repair the decoration quality problems caused by improper construction and materials of Party B;

3. During the warranty period, if the veneer is damaged or cannot be used normally due to improper use and maintenance by Party A, Party B shall charge maintenance fees as appropriate;

4. This guarantee shall come into effect after being signed and sealed by both parties.